Loading...
HomeMy WebLinkAboutRes 2014-12-15 Contract for Construction of Slayter Crk Influent Lift Station Project.pdfCITY OF ANNA, TEXAS RESOLUTION NO. 2014-12-15 A RESOLUTION OF THE CITY OF ANNA, TEXAS AUTHORIZING THE CITY MANAGER TO EXECUTE A CONTRACT FOR CONSTRUCTION OF THE SLAYTER CREEK WASTEWATER TREATEMENT PLANT INFLUENT LIFT STATION PROJECT. WHEREAS, one of the two existing screw pumps at the Slayter Creek wastewater treatment plant is inoperable, and the other screw pump is in poor condition and in danger of imminent failure; and, WHEREAS, failure of the second existing screw pump would render the Slayter Creek wastewater treatment plant inoperable; and, WHEREAS, City staff has proposed the construction of a submersible pump lift station to replace the existing screw pumps at the Slayter Creek wastewater treatment plant (the "Project"); and, WHEREAS, the City Council of the City of Anna, Texas (the "City Council") finds that prompt construction and timely completion of the submersible pump lift station is necessary to preserve and protect the public health and safety of the residents of the City of Anna, Texas (the "City"); and, WHEREAS, a procurement necessary to preserve or protect the public health or safety of the municipality's residents is generally exempt from the competitive bidding rules outlined in Chapter 252 of the Texas Local Government Code; and, WHEREAS, the City has solicited proposals for the emergency procurement and construction of the Project; NOW THEREFORE, BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF ANNA, TEXAS, THAT: Section 1. Recitals Incorporated. The recitals above are incorporated herein as if set forth in full for all purposes. Section 2. Authorization of Contract Award. The City Council hereby authorizes the City Manager to execute a contract for an amount not to exceed $500,000 for construction of the Slayter Creek Wastewater Influent Lift Station and authorizes, ratifies and approves the City Manager's execution of same. The City Manager is hereby authorized to execute all documents and to take all other actions necessary to finalize, act under, and enforce the Contract. RES. 2014-12-15 Contract for Construction of Slayter Crk Influent Lift Station Project PAGE 1 OF 2 12-16-14 PASSED AND APPROVED by the City Council of the City of Anna, Texas, on this 16th day of December 2014. ATTEST: APPROVED: Na a ilkison, City Secretary Mayor, Mike Crist i ' o RES. 2014-12-15 Contract for Construction of Slayter Crk Influent Lift Station Project PAGE 2 OF 2 12-16-14 CONTRACT AGREEMENT THIS WWTP Headworks Lift Station Rehabilitation (hereinafter this "Contract Agreement") entered into this by and between the CITY OF ANNA, TEXAS, a Texas ("Contractor"), located at_ WITNESSETH: - Emergency Procurement Contract day of , 20 municipal corporation, ("City") and WHEREAS, the City wishes to contract for the project identified as WWTP Headworks Lift Station Rehabilitation - Emergency Procurement (the "Project"); and WHEREAS, the Project shall include all work and activities necessary to complete the following scope of work (hereinafter referenced as "Work"): Slayter Creek Wastewater Treatment Plant Headworks Rehabilitation in accordance with the Contract Documents as that term is defined herein; and WHEREAS, the Contractor has represented to the City that its personnel are qualified to provide the Work required in this Contract Agreement in a professional, timely manner as time is of the essence; and WHEREAS, the City has relied upon the above representations by the Contractor; and WHEREAS, the City's consulting engineer has recommended that an agreement for aforesaid construction be entered into with the Contractor; NOW, THEREFORE, for and in consideration of these premises, of the mutual covenants herein set forth, and for other good and valuable consideration, the sufficiency of which is hereby acknowledged, the parties hereto hereby agree as follows: Section 1. DOCUMENTS INCORPORATED BY REFERENCE This Contract Agreement includes the recitals set forth above and the following documents: Notice to Contractors; Prevailing Wage Rates for Municipal Construction in Anna, Texas; Vendors Compliance to State Law; Conflicts of Interest Questionnaire; Affidavit Against Prohibited Acts; Proposal Form; Request for Certificate of Exemption from Texas Limited Sales, Excise and Use Tax; Contract Agreement; Performance Bond; Payment Bond; Maintenance Bond; Certificate of Insurance; jkledcakanna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -1 Contract Agreement Notice to Proceed; Any executed Change Orders; Supplementary General Provisions and Technical Specifications; and, Plans, Specifications and Drawings and all other documents made available to Contractor for his inspection in accordance with Proposal,' all of which are hereby incorporated herein by reference, whether or not attached hereto, and made a part hereof (hereinafter along with this Contract Agreement and referenced collectively as the "Contract" or "Contract Documents"). Change Orders issued hereafter, Construction Change Directives, a Direction for a Minor Modification in the Work issued by the City, and any other amendments executed by the City and the Contractor, shall become and be a part of the Contract Documents. Documents not included or expressly contemplated in this Section 1 do not, and shall not, form any part of the Contract. The Contract Documents are intended to be complementary, and a requirement in one document shall be deemed to be required in all documents. However, in the event of any conflict between any of the above -listed documents and this Contract Agreement, this Contract Agreement shall control. Section 2. REPRESENTATIONS OF THE CONTRACTOR In order to induce the City to execute the Contract and recognizing that the City is relying thereon, the Contractor, by executing the Contract, makes the following express representations to the City: 2.01 The Contractor is fully qualified to act as the general contractor for the Project and has, and shall maintain, any and all licenses, permits or other authorizations necessary to act as the general contractor for, and to construct the Project; 2.02 The Contractor has become familiar with the Project site and the local conditions under which the Project is to be constructed and operated; 2.03 The Contractor has received, reviewed and examined all of the documents which make up the Contract, including, but not limited to all plans and specifications, and has found them to the best of its knowledge, to be complete, accurate, adequate, consistent, coordinated and sufficient for construction. Section 3. INTENT AND INTERPRETATION With respect to the intent and interpretation of the Contract, the City and the Contractor agree as follows: 3.01 This Contract Agreement (along with its exhibits and other documents expressly referenced in Section 1, above), together with the Contractor's Performance Bond, Payment Bonds, and Maintenance Bonds for the Project constitute the entire and exclusive agreements between the parties with reference to the Project, and said Contract supersedes any and all prior discussions, communications, representations, understandings, negotiations, or agreements. 3.02 Anything that may be required, implied or reasonably inferred by the documents which make up the Contract, or any one or more of them, shall be provided by the Contractor with no increase to the Contract Price; 3.03 Nothing contained in the Contract shall create, nor be interpreted to create, privity or any other relationship whatsoever between the City and any person except the Contractor; If plans, specifications or drawings are too bulky or cumbersome to be physically bound, they are to be considered incorporated by reference into the aforementioned contract documents. JAcledcal\anna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -2 Contract Agreement 3.04 When a word, term, or phrase is used in the Contract, it shall be interpreted or construed first, as defined herein; second, if not defined, according to its generally accepted meaning in the construction industry; and third, if there is no generally accepted meaning in the construction industry, according to its common and customary usage; 3.05 Wherever the Contract calls for "strict" compliance or conformance with the Contract Documents as to matters—other than compliance with time limits, providing an updated schedule, and claim and change order procedures—the term shall mean within tolerances as described specifically in the Contract Documents, or if not specifically described, within industry standards and tolerances for deviation for the specific item or procedure in question; 3.06 The words "include", "includes", or "including", as used in the Contract, shall be deemed to be followed by the phrase, "without limitation"; 3.07 The listing herein of any items as constituting a material breach of the Contract shall not imply that any other, non listed item will not constitute a material breach of the Contract; 3.08 The Contractor shall have a continuing duty to read, examine, review, compare and contrast each of the documents which make up the Contract, shop drawings, and other submittals and shall give written notice to the City of any conflict, ambiguity, error or omission which the Contractor may find with respect to these documents, before proceeding with the associated part of the Work. The express or implied approval by the City or its designee of any shop drawings or other submittals shall not relieve the Contractor of the continuing duties imposed hereby, nor shall any such approval be evidence of the Contractor's compliance with the Contract. If the Contractor performs any activity knowing it involves an error, inconsistency or omission which was recognized, obvious, or reasonably should have been recognized, without such notice to the City, the Contractor shall assume responsibility for such performance and shall bear the costs for correction; 3.09 In the event of any conflict, discrepancy, or inconsistency among any of the documents which make up the Contract, the following shall control: (1) as between this Contract Agreement and any other document, this document shall govern; or, (2) in the case of any conflict, discrepancy or inconsistency among any of the other Contract Documents, and such conflict is not resolved by reference to the Supplementary General Provisions and Technical Specifications, then the Contractor shall notify the City immediately upon discovery of same for resolution. Section 4. CONTRACTOR'S PERFORMANCE The Contractor shall perform all of the Work required, implied or reasonably inferable from the Contract including, but not limited to, the following: 4.01 The Contractor will complete the entire Work described in the Contract Documents, except as specifically identified therein as the work of other parties or expressly excluded by specific reference, in accordance with the terms herein. 4.02 The furnishing of any and all required surety bonds and insurance certificate(s) and endorsement(s); 4.03 The provision or furnishing, and prompt payment therefor, of labor, supervision, services, materials, supplies, equipment, fixtures, appliances, facilities, tools, transportation, storage, disposal, power, fuel, heat, light, cooling, or other utilities, required for construction and all jAclerical\anna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -3 Contract Agreement necessary building permits and other permits or licenses required for the construction of the Project; 4.04 The creation and maintenance of a detailed and comprehensive copy of the drawings, specifications, addenda, change orders and other modifications depicting all as -built construction. Said items shall be submitted to the City, along with other required submittals upon Completion of the Project, and receipt of same by the City shall be a condition precedent to final payment to the Contractor. The Contractor shall prepare and submit final as -built drawings to the City. Section 5. TIME FOR CONTRACTOR'S PERFORMANCE; DELAYS 5.01 The Contractor shall commence the performance of the Contract on the date set forth in the Notice to Proceed issued by the City Manager or the City Manager's designee and shall diligently continue its performance to and until Completion of the Project. The Contractor shall accomplish Completion (as defined herein below) of the Project not more than Sixty (60) calendar days following the issuance of the Notice to Proceed, (sometimes hereinafter referred to as the "Contract Time"). This Contract Time includes Ten (10) inclement weather days. By signing the Contract, the Contractor agrees that the Contract Time is a reasonable time for accomplishing Completion of the Project and completion of the Project within the Contract Time is of the essence. 5.02 The Contractor shall pay the City the sum of $500 per day for each and every calendar day of unexcused delay in achieving Substantial Completion beyond the date set forth herein for Substantial Completion. Any sums due and payable hereunder by the Contractor shall be payable, not as a penalty, but as liquidated damages representing an estimate of delay damages likely to be sustained by the City, estimated at the time of executing the Contract. When the City reasonably believes that Substantial Completion will be inexcusably delayed, the City shall be entitled, but not required, to withhold from any amounts otherwise due the Contractor an amount then believed by the City to be adequate to recover liquidated damages applicable to such delays. If and when the Contractor overcomes the delay in achieving Substantial Completion, or any part thereof, for which the City has withheld payment, the City shall promptly release to the Contractor those funds withheld over and above what ultimately came due as liquidated damages; 5.03 The term "Substantial Completion", as used herein, shall mean the point at which, as certified in writing by the City's consulting architect/engineer or other appropriate independent contractor or representative and approved by the City, the Project is at a level of completion in strict compliance with the Contract such that the City or its designee can enjoy beneficial use or occupancy and can legally occupy, use or operate it in all respects, for its intended purpose. Partial use or occupancy of the Project shall not result in the Project being deemed substantially complete, and such partial use or occupancy shall not be evidence of Substantial Completion. 5.04 All limitations of time set forth herein are material and are of the essence of the Contract. 5.05 Contractor agrees to punctually and diligently perform all parts of the Work at the time scheduled in this Contract Agreement. In this connection, Contractor agrees that it will keep itself continually informed of the progress of the job and will, upon its own initiative, confer with the City so as to plan its Work in coordinated sequence with the work of the City, if any, and of others and so as to be able to expeditiously undertake and perform its work at the time most beneficial to the entire Project. The Contractor will be liable for any loss, costs, or damages sustained by the City for delays in performing the Work hereunder, other than for excusable delays, as set forth in 5.06 below, for which Contractor may be granted a reasonable extension of time. lAdedcal\anna\2014-132 slayter ckwwtp headworks\specs\tech-spec\11-agreement.doc CA -4 Contract Agreement 6.06 If the Contractor is delayed at any time in the progress of the Work by any separate contractor employed by the City, or by changes in the Work, or by labor disputes, fire, unusual delay in transportation, unusually severe weather conditions, unavoidable casualties, delays specifically authorized by the City, or by causes beyond the Contractor's control, avoidance, or mitigation, and without the fault or negligence of the Contractor and/or subcontractor or supplier at any tier, then the contract time shall be extended by Change Order for such reasonable time, if any, as the City may determine that such event has delayed the progress of the Work, or overall completion of the Work if the Contractor complies with the notice and documentation requirements set forth below. (1) If the Contractor is delayed, obstructed, hindered or interrupted for a period of time exceeding seven calendar days by any act or neglect of the City, an adjustment shall be made for any increase in the direct cost of performance of this contract (excluding profit, extended home office overhead, incidental or consequential damages or disruption damages) and the Contract modified in writing accordingly. The Contractor must assert its right under this section by giving written notice to the City Manager within10 calendar days of the beginning of a delay, obstruction, hindrance or interruption by the City. No adjustment shall be made for any delay, obstruction, hindrance or interruption after final payment under this contract or to the extent that performance would have been so delayed, obstructed, hindered or interrupted by any other cause, including, but not limited to concurrent cause or fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract. The direct costs described above shall be limited to those direct costs attributable solely to this project, and shall be subject to documentation and verification of costs as required by the City. If unit prices are established in the Contract Documents or subsequently agreed upon, they shall form the basis for cost calculations under any claims for delay. (2) Any claim for extension of time shall be made in writing to the City, not more than 10 calendar days from the beginning of the delay. The notice shall indicate the cause of delay upon the progress of Work. If the cause of the delay is continuing, the Contractor must give such written notice every 10 calendar days. Within 10 calendar days after the elimination of any such delay, the Contractor shall submit further documentation of the delay and a formal Change Order request for an extension of time for such delay. (3) The written request for a time extension shall state the cause of the delay, the number of calendar days extension requested, and such analysis and other documentation as is reasonably requested by the City to demonstrate a delay in the progress of the Work or the overall project completion. If the Contractor does not comply with the above notice and documentation requirements, the claim for the delay shall be waived by the Contractor. The above notice and documentation requirements shall also be a condition precedent to the Contractor's entitlement to any extension of time. (4) Extensions of time will be the contractor's primary remedy for any and all delays, obstructions, hindrances, or interference. Payment or compensation, for direct costs only (as set forth above), may be made to the Contractor for hindrances or delays solely caused by the City if such delays or hindrances are within the City's ability to control and are not partially caused by the Contractor or any of its agents, subcontractors or others for whom it is responsible. No payment or compensation will be made for interference, obstructions, hindrances or delays which are not solely caused by the City and which the City fails to cure after a reasonable period after written notice. (5) Without limitation, the City's exercise of its rights under provisions related to changes to the Work, regardless of the extent or number of such changes, or the City's exercise of any of its remedies or any requirement to correct or re -execute defective Work, shall not J:\c1eHca1\anna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -5 Contract Agreement under any circumstances be construed as delays, hindrances or interference compensable further than as described herein. Section 6. FIXED PRICE AND CONTRACT PAYMENTS 6.01 The City shall pay, and the Contractor shall accept, as full and complete payment for the Contractor's timely performance of its obligations hereunder the fixed price of $ The price set forth in this Section 6.01 shall constitute the Contract Price, which shall not be modified except by Change Order or adjustment pursuant to approved unit prices, if any, as provided in the Contract. 6.02 The City shall pay the Contract Price to the Contractor in accordance with the procedures set forth in this Section 6 and as set forth here: (1) On or before the 10th calendar day of each month after commencement of performance, but no more frequently than once monthly, the Contractor may submit a payment request for the period ending the last calendar day of the previous month (the "Payment Request"). Said Payment Request shall be in such format and include whatever supporting information as may be required by the City. Therein, the Contractor may request payment for 90% of that part of the Contract Price allocable to Contract requirements properly provided, labor, materials and equipment properly incorporated in the Project, and materials or equipment necessary for the Project and properly stored at the Project site (or elsewhere if offsite storage is approved in writing by the City), less the total amount of previous payments received from the City. Payment for materials stored offsite shall be at the discretion of the City and if approved, the Contractor shall provide appropriate documentation to substantiate materials are stored in a bonded warehouse or facility, title or other proof of ownership has been transferred to the City, and that materials have been purchased and paid for by the Contractor (copies of paid invoices must be submitted to the City with payment request). Risk of loss shall be borne by, and insurance must be provided by the Contractor while in storage, transit and use during construction. At 75% completion of the Contract, by dollar value, and at the option of the City, retainage may be reduced to 5% plus an additional amount as detailed in Section 6.06 below for any part of the Work that is defective or non -conforming and in Section 6.02 above for anticipated liquidated damages. (2) Amounts reflected in Change Orders may be included in Payment Requests to the extent they are not in dispute and subject to final approval of cost to the City for such changes in work. (3) Each Payment Request shall be signed by the Contractor and shall constitute the Contractor's representation that the quantity of Work has reached the level for which payment is requested, that the Work has been properly installed or performed in strict compliance with the Contract, and that the Contractor knows of no reason why payment should not be made as requested. (4) Thereafter, the City shall review the Payment Request and may also review the Work at the Project site or elsewhere to determine whether the quantity and quality of the work is as represented in the Payment Request and is as required by the Contract. The amount of each such payment shall be the amount approved for payment by the City less such amounts, if any, otherwise owing by the Contractor to the City or which the City shall have the right to withhold as authorized by the Contract, subject to approval by the City. Approval of the Contractor's Payment Requests shall not preclude the City from the exercise of any of its rights as set forth in 6.06 herein below. jAcledcal\anna\2014-132 slayler ck wwtp headworks\specs\tech-spec\11-agreemenl.doc CA -6 Contract Agreement (5) The submission by the Contractor of a Payment Request also constitutes an affirmative representation and warranty that all work for which the City has previously paid is free and clear of any lien, claim, or other encumbrance of any person whatsoever. As a condition precedent to payment, the Contractor shall, if required by the City, also furnish to the City properly executed waivers of lien or claim, in a form acceptable to the City, from all subcontractors, materialmen, suppliers or others having lien or claim rights, wherein said subcontractors, materialmen, suppliers or others having lien or claim rights, shall acknowledge receipt of all sums due pursuant to all prior Payment Requests and waive and relinquish any liens, lien rights or other claims relating to the Project site. Furthermore, the Contractor warrants and represents that, upon payment of the Payment Request submitted, title to all work included in such payment shall be vested in the City. 6.03 When payment is received from the City, the Contractor shall within seven calendar days pay all subcontractors, material men, laborers and suppliers the amounts they are due for the work covered by such payment. In the event the City becomes informed that the Contractor has not paid a subcontractor, material man, laborer, or supplier as provided herein, the City shall have the right, but not the duty, to issue future checks and payment to the Contractor of amounts otherwise due hereunder naming the Contractor and any such subcontractor, material man, laborer, or supplier as joint payees. The City shall notify the Contractor of its intent to implement such a procedure, and will give the Contractor a reasonable period to cure any such failure prior to implementing the procedure. Such joint -check procedure, if employed by the City, shall create no rights in favor of any person or entity beyond the right of the named payees to payment of the check as a co -payee and shall not be deemed to commit the City to repeat the procedure in the future. 6.04 Neither payment to the Contractor, full or partial utilization of the Project for any purpose by the City, nor any other act or omission by the City shall be interpreted or construed as an acceptance of any work of the Contractor not strictly in compliance with the Contract; 6.06 After written notice to the Contractor and a reasonable opportunity to cure, the City shall have the right to refuse to make payment, in whole or in part, and, if necessary, may demand the return of a portion or all of the amount previously paid to the Contractor due to: (1) The quality of a portion, or all, of the Contractor's work not being in accordance with the requirements of the Contract; (2) The quantity of the Contractor's work not being as represented in the Contractor's Payment Request, or otherwise; (3) The Contractor's rate of progress being such that, in the opinion of the City, Substantial Completion may be inexcusably delayed; (4) The Contractor's failure to use Contract funds, previously paid the Contractor by the City, to pay Contractor's Project -related obligations including, but not limited to, subcontractors, laborers and material and equipment suppliers; (5) Claims made, or likely to be made, against the City or its property for which the Contractor or its agents or subcontractors or others for whom it is responsible are, or reasonably appear to be at fault; (6) Loss caused by the Contractor; jAdedcal\anna\2014-132 slayter ck vnvtp headworks\specs\tech-spec\11-agreement.doc CA -7 Contract Agreement (7) The Contractor's failure or refusal to perform any of its obligations to the City, after written notice and a reasonable opportunity to cure as set forth above. In the event that the City makes written demand upon the Contractor for amounts previously paid by the City as contemplated in this Section 6.05, the Contractor shall promptly comply with such demand. The City's rights hereunder survive the term of this Contract Agreement, are not waived by final payment and/or acceptance, and are in addition to Contractor's obligations elsewhere herein. 6.06 When the Contractor believes that Substantial Completion has been achieved, the Contractor shall notify the City in writing and shall furnish a listing of those matters, if any, yet to be finished. The City will thereupon conduct a site review to confirm that the Project is in fact substantially complete. If the City, through its review, finds that the Contractor's work is not substantially complete, and is required to repeat all, or any portion, of such review, the Contractor shall bear the cost of such repeat site review(s), which cost may be deducted by the City from any payment then or thereafter due to the Contractor. Guarantees and equipment warranties required by the Contract shall commence on the date of Substantial Completion. Upon Substantial Completion, the City shall pay the Contractor an amount sufficient to increase total payments to the Contractor to 100% of the Contract Price less any amounts attributable to damages, and less 150% of the costs, as reasonably determined by the City, incurred for the City to complete any incomplete work, correcting and bringing into conformance all defective and nonconforming work, and handling any outstanding or threatened claims. Such a calculation by the City of costs for completing all incomplete work, correcting and bringing into conformance all defective and nonconforming work, and handling any outstanding or threatened claims shall not bar the City from exercising its stated rights elsewhere in the Contract, or otherwise as provided by law for any incomplete, defective or nonconforming work or claims that are discovered by the City after the date of making such calculation or after the date of any partial or final payment, whether or not such incomplete, defective or nonconforming work or claims were obvious or should have been discovered earlier. 6.07 When the Project is finally complete and the Contractor is ready for a final review, it shall notify the City thereof in writing. Thereupon, the City will perform a final site review of the Project. If the City concurs that the Project is complete in full accordance with the Contract and that the Contractor has performed all of its obligations to the City hereunder, the Contractor will furnish a final Approval for Payment to the City certifying to the City that the Project is complete and the Contractor is entitled to the remainder of the unpaid Contract Price, less any amount withheld pursuant to the Contract. If the City is unable to issue its final Approval for Payment and is required to repeat its final review of the Project, the Contractor shall bear the cost of such repeat review(s), which costs may be deducted by the City from the Contractor's final payment; 6.08 The City shall, subject to its rights set forth in Section 6.06 above and elsewhere in the Contract, endeavor to make final payment of all sums due the Contractor within 30 calendar days of the final Approval for Payment, with the exception of items in dispute or concerning which the City has exercised any of its rights to investigate or remove. Section 7. INFORMATION AND MATERIAL SUPPLIED BY THE CITY 7.01 The City has furnished to the Contractor, prior to the execution of this Contract Agreement, all written and tangible material in its possession relevant to the conditions at the site of the Project. Such written and tangible material has been furnished to the Contractor only in order to make complete disclosure of such material as being in the possession of the City and for no other purpose. By furnishing such material, the City does not represent, warrant, or guarantee its accuracy either in whole, in part, implicitly or explicitly, or at all. jAcledcal\anna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -8 Contract Agreement 7.02 Differing site conditions. The Contractor shall promptly, and before such conditions are disturbed, notify the City in writing of: (1) subsurface or latent physical conditions at the site differing materially from those indicated in the contract, or (2) unknown physical conditions at the site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in this contract. The City shall investigate the conditions, and if it finds that such conditions do materially so differ and cause an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the Work under the Contract, whether or not changed as a result of such conditions, an adjustment shall be made, through negotiation and mutual agreement, and the contract modified in writing accordingly. Section 8. CEASE AND DESIST ORDER/OWNER'S RIGHT TO PERFORM WORK 8.01 In the event the Contractor fails or refuses to perform the Work, or any separable part thereof, as required herein, or with the diligence that will ensure its proper, timely completion in accordance with the contract documents, the City may instruct the Contractor, by written notice, to cease and desist further Work, in whole or in part, or to correct deficient Work. Upon receipt of such instruction, the Contractor shall immediately cease and desist, or proceed, as instructed by the City. In the event the City issues such instructions to cease and desist, the Contractor must, within seven calendar days of receipt of the City's instructions, provide a written, verified plan to eliminate or correct the cause of the City's order, which plan appears to the City to be reasonable, actually attainable and in good faith. In the event that the Contractor fails and/or refuses to provide such a plan or diligently execute an approved plan, then the City shall have the right, but not the obligation, to carry out the Work, or any portion thereof, with its own forces, or with the forces of another contractor, and the Contractor shall be fully responsible and liable for the costs of the City performing such work, which costs may be withheld from amounts due to the Contractor from the City. The rights set forth herein are in addition to, and without prejudice to, any other rights or remedies the City may have against the Contractor. If Work completed by the City or other contractor affects, relates to, is to be attached onto or extended by later Work of the Contractor, the Contractor shall, prior to proceeding with the later Work, and to the extent visible, report any apparent defects or variance from the Contract requirements which would render the Contractor's later Work not in compliance with the Contract requirements or defective or not in compliance with warranties or other obligations of the Contractor hereunder. 8.02 The provisions of this section shall be in addition to the City's ability to remove portions of the Work from the Contract and complete it separately. Section 9. CONTRACTOR'S DUTIES, OBLIGATIONS AND RESPONSIBILITIES In addition to any and all other duties, obligations and responsibilities of the Contractor set forth in the Contract Documents, the Contractor shall have and perform the following duties, obligations and responsibilities to the City: 9.01 Reference is hereby made to the continuing duties set forth in Section 3.08 above, which are by reference hereby incorporated in this Section 9.01. The Contractor shall not perform work without adequate plans and specifications, or without, as appropriate, approved shop drawings, or other submittals. If the Contractor performs work knowing or believing, or if through exercise of reasonable diligence it should have known that such work involves an error, inconsistency or omission in the Contract without first providing written notice to the City, the Contractor shall be responsible for such work and shall correct same bearing the costs set forth in Section 3.08 above. j1cledral\anna\2014-132 slayter ck wMp headworks\specs\tech-spec\11-agreement.doc CA -9 Contract Agreement 9.02 All work shall strictly conform to the requirements of the Contract. To that end, the Contractor shall be solely responsible for and have control over construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work, unless otherwise specified in the Contract Documents; 9.03 The work shall be strictly supervised, the Contractor bearing full responsibility for any and all acts, errors or omissions of those engaged in the work on behalf of the Contractor, including, but not limited to, all subcontractors and their employees. The Contractor shall maintain an on- site superintendent while any portion of the Work is being performed. The Contractor shall operate exclusively in the capacity of the City's independent contractor as to all work it performs under the Contract, and not as an agent, employee, or representative of the City; 9.04 The Contractor hereby warrants that all laborers furnished under the Contract shall be qualified and competent to perform the tasks undertaken, that the product of such labor shall yield only first-class results, that all materials and equipment provided shall be new (unless otherwise specified) and of high quality, that the completed work will be complete, of high quality, without defects, and that all work strictly complies with the requirements of the Contract. Any work not strictly complying with the requirements of this the Contract shall constitute a breach of the Contractor's warranty. 9.06 The Contractor will be responsible for acquiring all required permit(s)—except as specifically stated in Section 22.01 below—and calling for all required or routine inspections. The Contractor will cooperate with and abide by the decision of inspectors having jurisdiction. Should the Contractor have a dispute with any inspector or entity having jurisdiction, the Contractor shall promptly notify the City Manager or the City Manager's designee. The Contractor shall comply with all legal requirements applicable to the work 9.06 The Contractor shall employ and maintain at the Project site only competent, qualified full time supervisory personnel. Key supervisory personnel assigned by the Contractor to this Project are as follows: NAME FUNCTION If at any time the City reasonably determines that any employee of the Contractor is not properly performing the Work in the best interest of the City or the Project, or is hindering the progress of the Work, or is otherwise objectionable, the City shall so notify the Contractor, which shall replace the employee as soon as possible, at no increased cost to the City. 9.07 The Contractor must submit to the City the Contractor's schedule for completing the work prior to submittal of the first application for payment. The City will not review any payment request until such schedule has been submitted and approved. Such schedule shall be in a form as specified in the Contract or which shall have been approved by the City Manager or the City Manager's designee, and which shall provide for expeditious and practicable construction of the Project. The Contractor's schedule shall be updated no less frequently than monthly (unless the parties otherwise agree in writing) and shall be updated to reflect conditions encountered from jAderical\anna\2014-132slayterckwwtp headworkslspecs\tech-spec\11-agreement.doc CA -10 Contract Agreement time to time and shall apply to the total project. Each such revision shall be furnished to the City. Strict compliance with the requirements of this Section 9.07 shall be a condition precedent to payment to the Contractor, and failure by the Contractor to strictly comply with said requirements shall constitute a material breach of the Contract. 9.08 The Contractor shall keep an updated copy of the Contract Documents at the site. Additionally, the Contractor shall keep a copy of approved shop drawings and other submittals. All of these items shall be available to the City during all regular business hours. 9.09 Shop drawings and other such submittals from the Contractor do not constitute a part of the Contract. The Contractor shall not do any work requiring shop drawings or other submittals unless such shall have been approved in writing by the City or as required by the Contract Documents. All work requiring approved shop drawings or other submittals shall be done in strict compliance with such approved documents or Contract requirements. However, approval by the City shall not be evidence that work installed pursuant thereto conforms with the requirements of the Contract, and shall not relieve the Contractor of responsibility for deviations from the Contract unless the City has been specifically informed of the deviation by a writing incorporated in the submittals and has approved the deviation in writing. The delivery of submittals shall constitute a representation by the Contractor that it has verified that the submittals meets the requirements of the Contract, or will do so, including field measurements, materials and field construction criteria related thereto. The City shall have no duty to review partial submittals or incomplete submittals. The Contractor shall have the duty to carefully review, inspect, examine and physically stamp and sign any and all submittals before submission of same to the City. 9.10 The Contractor shall maintain the Project site and adjacent areas affected by its work and/or the acts of its employees, materialmen and subcontractors in a reasonably clean condition during performance of the work. Upon substantial completion, the Contractor shall thoroughly clean the Project site of all debris, trash and excess materials or equipment. If the Contractor fails to do so, the City may complete the cleanup, by its own forces or by separate contract, and shall be entitled to charge the Contractor for same through the collection or withholding of funds through the mechanisms provided elsewhere in this Contract Agreement; 9.11 At all times relevant to the Contract, the Contractor shall permit the City and its consultants to enter upon the Project site and any offsite lay down areas, safety permitting, and to review or inspect the work and any materials on any such site, without formality or other procedure. 9.12 The Contractor recognizes that the City may enter into other contracts to perform work relating to the Project, or to complete portions of the Work itself. The Contractor shall ensure that its forces reasonably accommodate the forces of the City and other contractors hired by the City. The Contractor shall coordinate its schedule with the work of other contractors. If the Contractor claims that delay or damage results from these actions of the City, it shall promptly submit a claim as provided herein. 9.13 Protection of persons and property. (1) It shall be the responsibility of the Contractor to initiate, continue and supervise all safety programs and precautions in the performance of the terms of the Contract. The Contractor shall take reasonable precautions for the safety of, and shall provide reasonable protection to prevent damage, injury or loss to its employees, subcontractors' employees, employees of the City and members of the public, the Work itself and unassembled components thereof, and other property at the site or adjacent thereto. As jAcledcakanna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -11 Contract Agreement part of the Contractor's obligations hereunder, the Contractor shall erect and maintain all necessary and prudent safeguards, barriers, signs, warnings, etc. (2) With notice to the City, the Contractor shall promptly remedy loss or damage to the Work or any person or property described herein caused in whole or in part by the acts of the Contractor or any subcontractor, sub -subcontractor or materialman. This obligation shall be in addition to the requirements of Section 10 herein. The City may direct the Contractor to remedy known violations of applicable laws, rules, regulations, and interpretations related to safety when and if observed on the site. However, through exercising this authority the City shall not incur any obligations to monitor, initiate, continue, or supervise safety programs and precautions such to diminish the Contractor's primary role in same. The City shall have the right to report suspected safety violations to the Occupational Safety and Health Administration (OSHA) or other appropriate authorities. (3) The Contractor shall promptly notify the City upon discovery of any unidentified material which Contractor reasonably believes to be asbestos, lead, PCB, or other hazardous material, and shall immediately stop work in the affected area of the Project. The Contractor shall not be responsible for removal or other work with regard to such hazardous material unless otherwise agreed between the City and the Contractor. In the case of work stopped due to the discovery of hazardous materials, Section 6 shall apply to claims for delay, hindrance or interference. Work will resume in the affected area of the Project immediately after such time as the hazardous material has been removed or rendered harmless, as certified by an industrial hygienist to be engaged by the City. 9.14 The Contractor warrants to the Owner that materials and equipment furnished under the Contract are of good quality and new unless otherwise required or permitted under the Contract Documents, that the Work will be free from defects not inherent in the quality required or permitted, and that the Work will conform to the requirements of the Contract Documents. Work not conforming to these requirements, including substitutions not properly approved and authorized, may be considered defective. The Contractor's warranty excludes remedy for damage or defect caused by abuse, modifications not executed by the Contractor, improper or insufficient maintenance, improper operation, or normal wear and tear and normal usage. If required by the Owner, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment. Section 10. INDEMNITY Except for expenses or liabilities arising from the negligence of the City, the Contractor hereby expressly agrees to indemnify and hold the City harmless against any and all expenses and liabilities arising out of the performance or default of the Contract as follows: 10.01 Contractor shall indemnify, and hold harmless, to the maximum extent permitted by law, City and its officers, agents, employees, and consultants from and against any and all liability, damages, losses, (whether in contract or in tort, including personal injury, accidental death or property damage, and regardless, of whether the allegations are false, fraudulent or groundless), and costs (including reasonable attorney's fees, litigation, arbitration, mediation, appeal expenses incurred in any matter, including a proceeding to enforce this Section 10) which in whole or in part are caused by the negligence, recklessness or intentional wrongful misconduct of the Contractor and Persons employed by or utilized by the Contractor in Contractor's performance of this Contract Aareement. jAcWcaflanna\2014-132slayterckww1pheadworks\specs\tech-specl11-agreement.doc CA -12 Contract Agreement 10.02 Contractor's obligation to indemnify, defend and hold harmless shall remain in effect and shall be binding upon Contractor whether such injury or damage shall accrue, or may be discovered, before or after termination of the Contract. 10.03 Contractor's failure to comply with this section's provisions shall constitute a material breach upon which City may immediately terminate or suspend this Contract Agreement. Section 11. CLAIMS BY THE CONTRACTOR Claims by the Contractor against the City, other than for time extensions covered by Section 6 hereof, are subject to the following terms and conditions: 11.01 All Contractor claims against the City shall be initiated by a written claim submitted to the City. Notice of such claim shall be received by the City no later than either 10 calendar days after the event, or 10 calendar days after the first appearance of the circumstances causing the claim, whichever is sooner, and same shall set forth in detail all known facts and circumstances supporting the claim. Final costs associated with any claim upon which notice has been filed must be submitted in writing to the City within 30 calendar days after notice has been received; 11.02 The Contractor and the City shall continue their performance hereunder regardless of the existence of any claims submitted by the Contractor including claims set forth in Section 6 hereof; 11.03 In the event the Contractor discovers previously concealed and unknown site conditions which are materially at variance from those typically and ordinarily encountered in the general geographical location of the Project, the Contract Price may, with the approval of the City, be modified, either upward or downward, upon the written notice of claim made by either party within 10 calendar days after the first appearance to such party of the circumstances. Final costs must be submitted within 30 calendar days after such notice is received by the City, unless extended by written agreement of the parties. As a condition precedent to the City having any liability to the Contractor due to concealed and unknown conditions, the Contractor must give the City written notice of, and an opportunity to observe, such condition prior to disturbing it. The failure by the Contractor to give the written notice and make the claim as provided by this Section 11.03 and as required elsewhere under the Contract shall constitute a waiver by the Contractor of any rights arising out of or relating to such concealed and unknown condition; 11.04 In the event the Contractor seeks to make a claim for an increase in the Contract Price, as a condition precedent to any liability of the City therefor, unless emergency conditions exist, the Contractor shall strictly comply with the requirements of Section 11.01 above and such claim shall be made by the Contractor before proceeding to execute any work for which a claim is made. Failure to comply with this condition precedent shall constitute a waiver by the Contractor of any claim for additional compensation; 11.05 In connection with any claim by the Contractor against the City that would result in compensation in excess of the Contract Price, any liability of the City for the Contractor's cost in this regard shall be limited to those cost categories set forth in Section 13.07 below. Section 12. SUBCONTRACTORS 12.01 Prior to execution of the Contract, the Contractor shall have identified to the City in writing, those parties required to be listed on the proposal form as subcontractors on the Project. Any changes to this list at any time shall be subject to the prior approval of the City. The City shall, in writing, state any objections the City may have to one or more of such subcontractors. The Contractor shall not enter into a subcontract with an intended subcontractor to whom the City jkledcal\anna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -13 Contract Agreement objects. If at any time the City objects to a subcontractor, the Contractor shall solicit proposals from potential replacements and shall submit the three lowest proposals to the City, along with the Contractor's proposed choice as replacement. If the approved replacement subcontractor's cost is verified to be higher than the removed subcontractor, the excess shall be added to the Contract Price, unless the subcontractor in question has to be removed due to a default, or deficient performance. If the approved replacement subcontractor's cost is lower than the removed subcontractor, the difference shall be deducted from the Contract Price. Subcontractor markups shall be limited to those listed in Section 13.07 below. All subcontracts shall afford the Contractor rights against the subcontractor which correspond to those rights afforded to the City against the Contractor herein, including those rights of Contract termination as set forth herein below. 12.02 Each and every subcontract related to the Project is hereby assigned by the Contractor to the City, contingent upon the termination of the Contract for default or convenience as provided herein, and only as to those subcontracts which the City accepts in writing directed to the Contractor. This contingent assignment is subject to the prior rights of any surety obligated under a bond related to the Contract. This contingent assignment will operate prospectively from the effective date of assignment, and will not obligate the City to any liabilities existing on the effective date of the assignment, or arising from events, acts, failures to act, facts or circumstances existing prior to the effective date of the assignment. The contracts subject to this contingent assignment shall also be further assignable by the City, at the City's sole option. The Contractor shall bear the responsibility of notifying subcontractors of this contingent assignment and including it in all subcontracts in connection with the Project. Section 13. CHANGE ORDERS 13.01 The City Manager or the City Manager's express designee shall be the sole authorized representative of the City. Other than in matters of public safety or in time of emergency management, the Contractor shall not take direction or act upon information from any City personnel other than the City Manager's expressly authorized designee(s). 13.02 One or more changes to the work within the general scope of the Contract, may be ordered by Change Order. The City may also issue written directions for minor changes in the Work and may issue Construction Change Directives, as set forth below. The Contractor shall proceed with any such changes or Construction Change Directives without delay and in a diligent manner, and same shall be accomplished in strict accordance with the following terms and conditions: 13.03 Change Order shall mean a written order directed to the Contractor executed by the City after execution of the Contract, directing a change in the work. A Change Order may include a change in the Contract Price, (other than a change attributable to damages for delay as provided in Section 6 hereof), or the time for the Contractor's performance, or any combination thereof. Where there is a lack of total agreement on the terms of a Change Order or insufficient time to execute a bilateral change, the City may also direct a change in the Work in the form of a Construction Change Directive, which will set forth the change in the Work and the change, if any, in the Contract Price or time for performance, for subsequent inclusion in a Change Order; Construction Change Directives shall include a not -to -exceed preliminary price, against which the Contractor may begin billing (subject to the requirements for pay applications elsewhere herein) as the work is performed. j \cledcal\anna\2014-132 slayter ckwwtp headworks\specs\tech-spec\11-agreement.doc CA -14 Contract Agreement (1) The Contractor shall furnish a price breakdown, itemized as required and within the time specified by the City, with any proposal for a contract modification. (2) The price breakdown (a) must include sufficient detail to permit an analysis of all costs for material, labor, equipment and subcontracts, and (b) must cover all work involved in the modification, whether the work was deleted, added or changed. (3) The Contractor shall provide similar price breakdowns to support any amounts claimed for subcontracts. (4) The Contractor's proposal shall include a complete justification for any time extension proposed. 13.04 Any change in the Contract Price resulting from a Change Order shall be determined as follows: (1) By mutual agreement between the City and the Contractor as evidenced by (a) the change in the Contract Price being set forth in the Change Order, (b) such change in the Contract Price, together with any conditions or requirements relating thereto, being initialed by both parties and (c) the Contractor's execution of the Change Order; or, (2) If no mutual agreement occurs between the City and the Contractor, the change in the Contract Price, if any, shall be derived by determining the reasonable actual costs incurred or savings achieved, resulting from revisions in the work. Such reasonable actual costs or savings shall include a component for direct job site overhead and profit but shall not include home -office overhead or other indirect costs or components. The calculation of actual costs shall conform to the markup schedule in Section 13.07 below. Any such costs or savings shall be documented in the format, and with such content and detail as the City requires. The Contractor shall promptly submit such documentation and other supporting materials as the City may require in evaluating the actual costs incurred or to be incurred. 13.05 The execution of a Change Order by the Contractor shall constitute conclusive evidence of the Contractor's agreement to the ordered changes in the work, the Contract as thus amended, the Contract Price and the time for performance by the Contractor, regardless of the nature, amount or extent of the changes. The Contractor, by executing the Change Order, waives and forever releases any claim against the City for additional time or compensation for matters relating to, arising out of or resulting from the work included within or affected by the executed Change Order of which the Contractor knew or should have known. 13.06 The Contractor shall notify and obtain the consent and approval of the Contractor's surety with reference to all Change Orders if such notice, consent or approval are required by the City, the Contractor's surety or by law. The Contractor's execution of the Change order shall constitute the Contractor's warranty to the City that the surety has been notified of, and consents to, such Change Order and the surety shall be conclusively deemed to have been notified of such Change Order and to have expressly consented thereto. jAc1edcal\anna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -15 Contract Agreement 13.07 For the purpose of Change Orders, the following definitions of terms and other restrictions apply: Contractor's or Subcontractor's Materials shall include the cost of materials, sales tax, and the cost of all transport. The cost of items listed shall be directly related to the Change Order. Indirect costs not specifically related to the Change Order shall not be considered. Contractor's or Subcontractor's Direct Labor Cost shall be limited to the hourly rate of directly involved workmen, employer contributions towards company standard benefits, pensions, unemployment or social security (if any), and employer costs for paid sick and annual leave. Contractor's or Subcontractor's Overhead shall include license fees, bond premiums, supervision, wages of timekeepers and clerks, incidentals, home and field office expense, and vehicle expense directly related to the Project, and all other direct Project expenses not included in the Contractor's materials, direct labor, and equipment costs. The allowance for Overhead and Profit shall be limited to the following schedule: 1. For the Contractor, for any work performed by the Contractor's own forces, 10% of the Subtotal of Costs to the Contractor. 2. For the Contractor, for any work performed by his Subcontractor, 5% of the amount due the Subcontractor. 3. For each Subcontractor or Sub -subcontractor involved, for any work performed by their own forces, 10% of their materials and direct labor costs. 4. For each Subcontractor, for work performed by his Sub-subcontractor(s), 5% of the amount due the Sub -subcontractor. For Change Orders, the total cost or credit to the Owner shall be based on the following schedule: Contractor's Materials Cost + Contractor's Direct Labor Costs + Contractor's Equipment Costs (includes owned/rental equipment)2 + Applicable Subcontractor Costs = Subtotal of Costs to the Contractor + Contractor's Overhead and Profit = Total Cost or Credit to the Owner 13.08 Nothing Contained in this section shall be deemed to contradict or limit the terms of Section 6.05 above. 2 Owned Equipment For equipment owned by the Contractor, actually used in Change Order work including sales tax, or any related business entity, regardless of whether Contractor leases such equipment from the related business entity, the cost shall be the lesser of (i) the Contractor's actual ownership cost, or (ii) 85% of the applicable ownership cost listed in the most recent edition of the Contractor's Equipment Cost Guide, published by Dataquest. Third Party Rental Equipment For equipment actually rented by the Contractor, actually used in Change Order work including sales tax, from an unrelated third party, the cost shall be the lesser of (i) the Contractor's actual rental cost, or (ii) 85% of the applicable equipment rates based on the most recent edition of the Rental Rate Bluebook for Construction published by Dataquest. A reasonable rental cost shall be allowed as determined by the City Manager or the City Manager's designee when machinery and construction equipment not so listed is required. jAc1edral\anna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -16 Contract Agreement Section 14. DISCOVERING AND CORRECTING DEFECTIVE OR INCOMPLETE WORK 14.01 In the event that the Contractor covers, conceals or obscures its work in violation of the Contract or in violation of an instruction from the City, such work shall be uncovered and displayed for review by the City and/or its consultants upon request, and shall be reworked at no cost in time or money to the City. 14.02 If any of the work is covered, concealed or obscured in a manner not covered by Section 14.01 above, it shall, if directed by the City, be uncovered and displayed for the City and/or its consultants. If the uncovered work conforms strictly with the Contract, the costs incurred by the Contractor to uncover and subsequently, replace such work shall be borne by the City. Otherwise, such costs shall be borne by the Contractor. 14.03 The Contractor shall, at no cost in time or money to the City, correct work rejected by the City as defective or failing to conform to the Contract. Additionally, the Contractor shall reimburse the City for all testing, review, inspections and other expenses incurred as a result thereof. 14.05 In addition to its warranty obligations set forth elsewhere in this Contract Agreement and any manufacturer's warranties provided on the Project, and in addition to other remedies provided herein or by law to the City, the Contractor shall be specifically obligated to promptly correct any and all defective or nonconforming work, whether obvious or after -discovered, for a period of 12 months following Substantial Completion upon written direction from the City. 14.06 The City may, but shall in no event be required to, choose to accept defective or nonconforming work. In such event, the Contract Price shall be reduced by the greater of (1) the reasonable costs of removing and correcting the defective or nonconforming work, or (2) the difference between the fair market value of the Project as constructed and the fair market value of the Project had it not been constructed in such a manner as to include defective or nonconforming work. If the remaining portion of the unpaid Contract Price, if any, is insufficient to compensate the City for the acceptance of defective or nonconforming work, the Contractor shall, upon written demand from the City, pay the City such remaining compensation for accepting defective or nonconforming work. The Contractor shall have an opportunity to correct any defect or non- conformance prior to the City taking the above actions. The contractor, upon written notice of any defect or non-conformance, shall have 10 calendar days to make corrections, unless the City agrees that the correction will require more than 10 calendar days to correct. Section 15. CITY'S RIGHT TO SUSPEND CONTRACTOR'S PERFORMANCE 15.01 In addition to the City's rights under Section 8 and elsewhere in this Contract Agreement, the City shall have the right at any time to direct the Contractor to suspend its performance, or any designated part thereof when in the interests of the City. If any such suspension is directed by the City, the Contractor shall immediately comply with same. 15.02 In the event the City directs a suspension of performance under this section, through no fault of the Contractor, if the suspension is lifted other than by Termination, the City shall pay the Contractor as full compensation for such suspension the Contractor's ordinary and reasonable costs, actually incurred and paid, of: (1) demobilization and remobilization, including such justifiable costs paid to subcontractors (cost categories and markups limited to those set forth in Section 13.07 above); (2) preserving and protecting work in place; j \cledral\anna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -17 Contract Agreement (3) approved storage of materials or equipment purchased for the Project, including insurance thereon; and (4) substantiated extended field office overhead (but no home -office overhead). 15.03 The City may order suspension of the Work in whole or in part for such time as deemed necessary because of the failure of the Contractor to comply with any of the requirements of this Contract Agreement, and the Contract Agreement's completion date shall not be extended on account of any such suspension of Work. When the City orders any suspension of the Work under this Section 15.03, the Contractor shall not be entitled to any payment for Work which the Contractor performs after notice of suspension and/or during the suspension period and shall not be entitled to any costs or damages resulting from such suspension. 15.04 The City's rights under this section shall be in addition to those contained elsewhere in the Contract or provided by law. Section 16. TERMINATION BY THE CITY The City may terminate the Contract in accordance with the following terms and conditions: 16.01 Termination for Convenience. The City may, when in the interests of the City, terminate performance under the Contract by the Contractor, in whole or in part, for the convenience of the City. The City shall give written notice of such termination to the Contractor specifying when termination becomes effective. The Contractor shall incur no further obligations in connection with the work so terminated, other than warranties and guarantees for completed work and installed equipment, and the Contractor shall stop work when such termination becomes effective. The Contractor shall also terminate outstanding orders and subcontracts for the affected work. The Contractor shall settle the liabilities and claims arising out of the termination of subcontracts and orders. The City may direct the Contractor to assign the Contractor's right, title and interest under termination orders or subcontracts to the City or its designee. The Contractor shall transfer title and deliver to the City such completed or partially completed work and materials, equipment, parts, fixtures, information and Contract rights as the Contractor has in its possession or control. When terminated for convenience, the Contractor shall be compensated as follows: (1) The Contractor shall submit a termination claim to the City specifying the amounts due because of the termination for convenience together with costs, pricing or other data required by the City. If the Contractor fails to file a termination claim within six months from the effective date of termination, the City shall pay the Contractor, an amount derived in accordance with subsection (3) below. (2) The owner and the Contractor may agree to the compensation, if any, due to the Contractor hereunder. (3) Absent agreement to the amount due to the Contractor, the owner shall pay the Contractor the following amounts: (a) Contract costs for labor, materials, equipment and other services accepted under the Contract; (b) Reasonable costs incurred in preparing to perform and in performing the terminated portion of the work, and in terminating the Contractor's performance, plus a fair and reasonable allowance for direct job site overhead and earned jAdedcal\anna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -18 Contract Agreement profit thereon (such profit shall not include anticipated profit or consequential damages); provided however, that if it reasonably appears that the Contractor would have not profited or would have sustained a loss if the entire Contract would have been completed, no profit shall be allowed or included and the amount of compensation shall be reduced to reflect the anticipated rate of loss, if any; (c) Reasonable costs of settling and paying claims arising out of the termination of subcontracts or orders pursuant to Subsection (3)(a) above—if contingent assignment of such contracts has not been elected as provided herein—shall not include amounts paid in accordance with other provisions of the Contractor. This clause is subject to and the Contractor shall be limited by the City's rights to direct the replacement of subcontractors under Section 12.01. The total sum to be paid the Contractor under this Subsection (3) shall not exceed the total Contract Price, as properly adjusted, reduced by the amount of payments otherwise made, and shall in no event include duplication of payment. 16.02 Termination for Cause. If the Contractor does not perform the work, or any part thereof, in a timely manner, supply adequate labor, supervisory personnel or proper equipment or materials, or if it fails to timely discharge its obligations for labor, equipment and materials, or proceeds to disobey applicable law, or otherwise commits a violation of a material provision of the Contract, then the City, in addition to any other rights it may have against the Contractor or others, may terminate the performance of the Contractor, in whole or in part at the City's sole option, and assume possession of the Project site and of all materials and equipment at the site and may complete the work. In such case, the Contractor shall not be paid further until the work is complete. After Completion has been achieved, if any portion of the Contract Price, as it may be modified hereunder, remains after the cost to the City of completing the work, including all costs and expenses of every nature incurred, has been deducted by the City, such remainder shall belong to the Contractor. Otherwise, the Contractor shall pay and make whole the City for such cost. This obligation for payment shall survive the termination of the Contract. In the event the employment of the Contractor is terminated by the City for cause pursuant to this Section 16.02 and it is subsequently determined by a Court of competent jurisdiction that such termination was without cause, such termination shall thereupon be deemed a Termination for Convenience under Section 16.01 and the provisions of Section 16.01 shall apply. 16.03 Termination for Non -Appropriation. The City may also terminate the Contract, in whole or in part, for non -appropriation of sufficient funds to complete or partially complete the Project, regardless of the source of such funds, and such termination shall be on the terms of Section 16.01. 16.04 The City's rights under this Section shall be in addition to those contained elsewhere herein or provided by law. Section 17. INSURANCE 17.01 Contractor shall be responsible for all damage to person and or property resulting from its negligent acts, reckless or intentional misconduct, errors or omissions or those of their subcontractors, agents or employees in connection with such services and shall be responsible for all parts of its work, both temporary and permanent. jAdedral\anna\2014-132 slayter ck wwtp headworks\specs\tech-spec111-agreement.doc CA -19 Contract Agreement 17.02 Contractor shall, at its own expense, procure and maintain throughout the term of this Contract Agreement, with insurers acceptable to City, the types and amounts of insurance conforming to the minimum requirements set forth in this Contract Agreement. Contractor shall not commence work until the required insurance is in force and evidence of insurance acceptable to City has been provided to, and approved by, City. An appropriate Certificate of Insurance shall be satisfactory evidence of insurance. Until such insurance is no longer required by the Contract, Contractor shall provide City with renewal or replacement evidence of insurance at least 30 days prior to the expiration or termination of such insurance. 17.03 Workers' Compensation/Employer's Liability Insurance Worker's Compensation Insurance in accordance with statutory requirements, and Employers' Liability Insurance with limits of not less than $1,000,000 for each accident. General Liability Insurance Comprehensive General Liability Insurance with bodily injury limits of not less than $1,000,000 for each occurrence and not less than $1,000,000 in the aggregate, and with property damage limits of not less than $1,000,000 for each occurrence and not less than $1,000,000 in the aggregate. Automobile Liability Insurance Automobile Liability Insurance with bodily injury limits of not less than $1,00,000 for each person and not less than $1,000,000 for each accident, and with property damage limits of not less than $1,000,000 for each accident. 17.04 Contractor shall furnish insurance certificates or insurance policies at the City's request to evidence such coverages. Except for workers compensation, the insurance policies shall name the City as an additional insured, and shall contain a provision that such insurance shall not be canceled or reduced with respect to by coverages or endorsements without 30 days' prior written notice to OWNER and CONSULTANT. In such event, CONSULTANT shall, prior to the effective date of the change or cancellation, serve substitute policies furnishing the same coverage. 17.05 Compliance with these insurance requirements shall not limit the liability of Contractor. Any remedy provided to the City by any insurance maintained by the Contractor shall be in addition to and not in lieu of any other remedy (including, but not limited to, as an indemnitee of Contractor) available to the City under the Contract or otherwise. 17.06 Neither approval nor failure to disapprove insurance furnished by Contractor shall relieve Contractor from responsibility to provide insurance as required by this Contract Agreement. 17.07 Contractor shall deliver to City the required certificate(s) of insurance and endorsement(s) before City signs this Contract Agreement. 17.08 Contractor's failure to obtain, pay for, or maintain any required insurance shall constitute a material breach upon which City may immediately terminate or suspend this Contract Agreement. In the event of any termination or suspension, City may use the services of another consultant or consultants, without City's incurring any liability to Contractor. 17.09 At its sole discretion, City may obtain or renew Contractor insurance, and City may pay all or part of the premiums. Upon demand, Contractor shall repay CITY all monies paid to obtain or renew the insurance. City may offset the cost of the premium against any monies due Contractor from City. jActedcahanna\2014-132 slayter ck wwlp headworks\specs\tech-spec\11-agreement.doc CA -20 Contract Agreement 17.10 The Contractor shall furnish to the City Certificates of Insurance allowing thirty (30) days notice for any change, cancellation, or non -renewal. Such Certificates shall contain the following wording: "SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL MAIL 30 DAYS PRIOR WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED HEREIN." If the insurance policies expire during the terms of the Contract, a renewal certificate or binder shall be filed with the City at least 30 days prior to the renewal date. 17.11 In addition to the coverages required herein, the Contractor shall furnish and maintain all-risk builder's risk property insurance, satisfactory to the City, upon the entire Work at the site to the full replacement cost of the completed project. This coverage shall name City as an additional insured, must include the interests of the Contractor, subcontractors and sub -subcontractors in the Work, and must be procured from an insurer licensed to do business in the State of Texas with a Best's rating of "A+, A, A-". The policy must insure against perils including, but not limited to, earthquake, fire, extended coverages, windstorm, lightning, flood, and physical loss or damage, including theft, vandalism and malicious mischief. Section 18. PERFORMANCE AND PAYMENT BONDS 18.01 Contractor shall provide City with a Performance Bond, a Payment Bond, and a Maintenance Bond meeting the standards specified in the Contract Documents, on the forms provided by the City, and attached hereto, with a Power of Attorney Affidavit, each in an amount not less than the Contract price. 18.02 Sureties' qualifications. All bonds, to the extent required under the Contract, including, but not by way of limitation, any Performance Bond, Payment Bond, or Maintenance Bond shall be written through a reputable and responsible surety bond agency licensed to do business in the State of Texas and with a surety which holds a certificate of authority authorizing it to write surety bonds in Texas and maintains a current certificate of authority as an acceptable surety on Federal Bonds in accordance with U.S. Department of Treasury Circular 570. However, if the amount of the bond exceeds the underwriting limitations set forth in the Circular, in order to qualify, the net retention of the surety company shall not exceed the underwriting limitation in the Circular and the excess risk must be protected by co-insurance, reinsurance, or other methods in accordance with Treasury Circular 297, revised September 1, 1978 (3) CFR Section 223.10 - Section 223.111 and the surety company shall provide the City with evidence satisfactory to the City, that such excess risk has been protected in an acceptable manner. 18.03 Additional or replacement bond. It is further mutually agreed between the parties hereto that if, at any time, the City shall deem the surety or sureties upon any bond to be unsatisfactory, or if, for any reason, such bond (because of increases in the work or otherwise) ceases to be adequate, the Contractor shall, at its expense within five days after the receipt of notice from the City so to do, furnish an additional or replacement bond or bonds in such form, amount, and with such surety or sureties as shall be satisfactory to the City. In such event, no further payments to the Contractor shall be deemed to be due under the Contract until such new or additional security for the faithful performance of the work shall be furnished in manner and form satisfactory to the City. 18.04 As applicable to all bonds required under the Contract, the surety company shall have a Texas agent whose name shall be listed in the prescribed space on the forms provided by the City for all bonds required by the City, or otherwise listed therein if the form of the Bond is not prescribed by the City. jAcledcahanna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreemenl.doc CA -21 Contract Agreement Section 19. PROJECT RECORDS All documents relating in any manner whatsoever to the Project, or any designated portion thereof, which are in the possession of the Contractor, or any subcontractor of the Contractor, shall be made available to the City and/or its consultants for inspection and copying upon written request by the City. Furthermore, said documents shall be made available, upon request by the City, to any state, federal or other regulatory authority and any such authority may review, inspect and copy such records. Said records include, but are not limited to, all drawings, plans, specifications, submittals, correspondence, minutes, memoranda, tape recordings, videos, or other writings or things which document the Project, its design, and its construction. Said records expressly include those documents reflecting the cost of construction to the Contractor. The Contractor shall maintain and protect these documents for not less than three years after completion of the Project, or for any longer period of time as may be required by law or good construction practice. The Contractor further agrees to include these provisions in any subcontracts issued by him in connection with this Contract Agreement. Section 20. APPLICABLE LAW The laws of the State of Texas shall govern this Contract Agreement. In any litigation arising under this Contract Agreement, the parties agree to a waiver of the right to a trial before a jury, and all such litigation shall be litigated only in a non -jury hearing in Collin County, Texas. Section 21. SUCCESSORS AND ASSIGNS Each party binds itself, its successors, assigns, executors, administrators or other representatives to the other party hereto and to successors, assigns, executors, administrators or other representatives of such other party in connection with all terms and conditions of the Contract. The Contractor shall not assign the Contract without prior written consent of the City. Section 22. MISCELLANEOUS PROVISIONS 22.01 Construction Permits. The City hereby agrees to waive the charge for a City -issued building permit for this Project. However, the Contractor is responsible for obtaining all permits or fees otherwise required of the Contractor by the Contract Documents, or permits and fees customarily the responsibility of the Contractor. 22.02 Compliance By Contractor: Nondiscrimination. Contractor shall comply with all Federal, State and local laws, ordinances, rules and regulations of any authorities throughout the duration of the Contract. The Contractor shall be responsible for compliance with any such law, ordinance, rule or regulation and shall hold City harmless and indemnify same in the event of non- compliance. Contractor further agrees to abide by the requirements under Federal Executive Order Number 11246, as amended, including specifically the provisions of the equal opportunity clause. 22.03 State and Local Taxes. Except as otherwise provided, contract prices shall include all applicable state and local taxes. Contractor shall indemnify and hold harmless the City for any loss, cost or expense incurred by, levied upon or billed to the City as a result of Contractor's failure to pay any tax of any type due in connection with this Contract Agreement. Contractor shall ensure that the above sections are included in all subcontracts and sub -subcontracts, and shall ensure withholding on out of state sub and sub -subcontractors to which withholding is applicable. jAcleheakanna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -22 Contract Agreement 22.04 Any and all notices required to be sent under the Contract or otherwise shall be sent to the following: If to the City: City of Anna Attn: City Manager 111 North Powell Parkway P.O. Box 776 Anna, Texas 79406 If to the Contractor: Section 23. ENTIRE AGREEMENT Aside from duly authorized Change Orders, any modification to this Contract Agreement must be supported by an additional, articulated consideration, and must either be in writing, executed by the parties hereto, or, if made orally, should be confirmed in writing, which writing should state the consideration which supports the modification. Failure to confirm an oral modification in writing shall constitute a waiver of any claim for additional compensation with regard to the oral modification. Nothing in this Section shall be construed to limit the City's authority to issue changes set forth in Section 14 herein. Section 24. SEVERABILITY If any term or condition of the Contract or the application thereof to any person(s) or circumstances is held invalid, this invalidity shall not affect other terms, conditions or applications which can be given effect without the invalid term, condition, or application. To this end, the terms and conditions of the Contract are agreed to be severable. Section 25. WAIVER Waiver of any breach of any term or condition of this contract shall not be deemed a waiver of any prior or subsequent breach, and shall not entitle any party hereto to any subsequent waiver of any terms hereunder. No term or condition of this contract shall be held to be waived, modified or deleted except by an instrument, in writing, signed by the parties hereto. j1cledcalianna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -23 Contract Agreement IN WITNESS WHEREOF, the Parties have executed this Contract Agreement under their respective seals on the day and year first written above. CITY OF ANNA, TEXAS Philip Sanders, City Manager ATTEST: Natha Wilkison, City Secretary (SEAL) (Contractor) 9W ATTEST: SECRETARY (SEAL) (name and title of authorized representative) jAcleftal\anna\2014-132 slayter ck wwtp headworks\specs\tech-spec\11-agreement.doc CA -24 Contract Agreement